DEFINITIONS

As used herein and throughout these Service Terms:

1.1 Service Terms means the entire content of this Service Terms document, the Proposal document(s), Schedule A, together with any other Supplements designated below, together with any exhibits, schedules or attachments hereto.

1.2 Client Content means all materials, information, photography, writings and other creative content provided by Client for use in the preparation of and/or incorporation in the Deliverables.

1.3 Copyrights mean the property rights in original works of authorship, expressed in a tangible medium of expression, as defined and enforceable under Indian Copyright Law.

1.4 Deliverables means the services and work product specified in the Proposal to be delivered by Developer to Client, in the form and media specified in the Proposal.

1.5 Developer Tools means all design tools developed and/or utilized by Developer in performing the Services, including without limitation pre-existing and newly developed software including source code, Web authoring tools, type fonts, and application tools, together with any other software, or other inventions whether or not patentable, and general non-copyrightable concepts such as website design, architecture, layout, navigational and functional elements.

1.6 Final Art means all creative content developed or created by Developer, or commissioned by Developer, exclusively for the Project and incorporated into and delivered as part of the Final Deliverables, including and by way of example, not limitation, any and all visual designs, visual elements, graphic design, illustration, photography, animation, sounds, typographic treatments and text, modifications to Client Content, and Developer’s selection, arrangement and coordination of such elements together with Client Content and/or Third Party Materials.

1.7 Final Deliverables means the final versions of Deliverables provided by Developer and accepted by Client.

1.8 Preliminary Works means all artwork including, but not limited to, concepts, sketches, visual presentations, or other alternate or preliminary designs and documents developed by Developer and which may or may not be shown and or delivered to Client for consideration but do not form part of the Final Art.

1.9 Project means the scope and purpose of the Client’s identified usage of the work product as described in the Proposal.

1.10 Services means all services and the work product to be provided to Client by Developer as described and otherwise further defined in the Proposal.

1.11 Third Party Materials means proprietary third party materials which are incorporated into the Final Deliverables, including without limitation stock photography or illustration.

1.12 Trademarks means trade names, words, symbols, designs, logos or other devices or designs used in the Final Deliverables to designate the origin or source of the goods or services of Client.

  1. PROPOSAL

The terms of the proposal shall be effective for 2 days after presentation to Client. In the event this Service Terms is not executed by Client within the time identified, the Proposal, together with any related terms and conditions and deliverables, may be subject to amendment, change or substitution.

  1. FEES AND CHARGES

3.1 Fees. In consideration of the Services to be performed by Developer, Client shall pay to Developer fees in the amounts and according to the payment schedule set forth in the Proposal, and all applicable sales, use or value added taxes, even if calculated or assessed subsequent to the payment schedule.

3.2 Additional Costs. The Project pricing includes Developer’s fee, 1 year shared hosting & 1 year standard maintenance charges. Any and all outside costs including, but not limited to, equipment rental, photographer’s costs and fees, photography and/or artwork licenses, prototype production costs, talent fees, music licenses and online access, will be billed to Client unless specifically otherwise provided for in the Proposal.

3.3 Invoices. All invoices are payable within 7 days of receipt. A monthly service charge of 1.5% [or the greatest amount allowed by state law] is payable on all overdue balances. Payments will be credited first to late payment charges and next to the unpaid balance. Client shall be responsible for all collection or legal fees necessitated by lateness or default in payment. Developer reserves the right to withhold delivery and any transfer of ownership of any current work if accounts are not current or overdue invoices are not paid in full. All grants of any license to use or transfer of ownership of any intellectual property rights under this Service Terms are conditioned upon receipt of payment in full which shall be inclusive of any and all outstanding Additional Costs, Taxes, Expenses, and Fees, Charges, or the costs of Changes.

  1. CHANGES

4.1 General Changes. Unless otherwise provided in the Proposal, and except as otherwise provided for herein, Client shall pay additional charges for changes requested by Client which are outside the scope of the services on a time and materials basis, at Developer’s standard hourly rate of Rs. 1000 per hour or a fixed price decided on mutual terms. Such charges shall be in addition to all other amounts payable under the Proposal, despite any maximum budget, contract price or final price identified therein. Developer may extend or modify any delivery schedule or deadlines in the Proposal and Deliverables as may be required by such Changes.

4.2 Substantive Changes. If Client requests or instructs Changes that amount to a revision of at least 15% of the time required to produce the Deliverables, and or the value or scope of the Services, Developer shall be entitled to submit a new and separate Proposal to Client for written approval. Work shall not begin on the revised services until a fully signed revised Proposal and, if required, any additional retainer fees are received by Developer.

4.3 Timing. Developer will prioritize performance of the Services as may be necessary or as identified in the Proposal, and will undertake commercially reasonable efforts to perform the Services within the time(s) identified in the Proposal. Client agrees to review Deliverables within the time identified for such reviews and to promptly either, (i) approve the Deliverables in writing or (ii) provide written comments and/or corrections sufficient to identify the Client’s concerns, objections or corrections to Developer. The Developer shall be entitled to request written clarification of any concern, objection or correction. Client acknowledges and agrees that Developer’s ability to meet any and all schedules is entirely dependent upon Client’s prompt performance of its obligations to provide materials and written approvals and/or instructions pursuant to the Proposal and that any delays in Client’s performance or Changes in the Services or Deliverables requested by Client may delay delivery of the Deliverables. Any such delay caused by Client shall not constitute a breach of any term, condition or Developer’s obligations under this Service Terms.

4.4 Testing and Acceptance. Developer will exercise commercially reasonable efforts to test Deliverables requiring testing and to make all necessary corrections prior to providing Deliverables to Client. Client, within 5 business days of receipt of each Deliverable, shall notify Developer, in writing, of any failure of such Deliverable to comply with the specifications set forth in the Proposal, or of any other objections, corrections, changes or amendments Client wishes made to such Deliverable. Any such written notice shall be sufficient to identify with clarity any objection, correction or change or amendment, and Developer will undertake to make the same in a commercially timely manner. Any and all objections, corrections, changes or amendments shall be subject to the terms and conditions of this Service Terms. In the absence of such notice from Client, the Deliverable shall be deemed accepted.

  1. CLIENT RESPONSIBILITIES

Client acknowledges that it shall be responsible for performing the following in a reasonable and timely manner:

(a) Coordination of any decision-making with parties other than the Developer;

(b) Provision of Client Content in a form suitable for reproduction or incorporation into the Deliverables without further preparation, unless otherwise expressly provided in the Proposal; and

(c) Final proofreading and in the event that Client has approved Deliverables but errors, such as, by way of example, not limitation, typographic errors or misspellings, remain in the finished product, Client shall incur the cost of correcting such errors.

(d) Client is supposed to respond on the emails within 24 hours of receiving the same. Any further delay would be added to the timeline of the project delivery.

  1. ACCREDITATION/PROMOTIONS

All displays or publications of the Deliverables shall bear accreditation and/or copyright notice in Developer’s name in the form, size and location as incorporated by Developer in the Deliverables, or as otherwise directed by Developer. Developer retains the right to reproduce, publish and display the Deliverables in Developer’s portfolios and websites, and in galleries, design periodicals and other media or exhibits for the purposes of recognition of creative excellence or professional advancement, and to be credited with authorship of the Deliverables in connection with such uses. Either party, subject to the other’s reasonable approval, may describe its role in relation to the Project and, if applicable, the services provided to the other party on its website and in other promotional materials, and, if not expressly objected to, include a link to the other party’s website.

  1. CONFIDENTIAL INFORMATION

Each party acknowledges that in connection with this Service Terms it may receive certain confidential or proprietary technical and business information and materials of the other party, including without limitation Preliminary Works (“Confidential Information”). Each party, its agents and employees shall hold and maintain in strict confidence all Confidential Information, shall not disclose Confidential Information to any third party, and shall not use any Confidential Information except as may be necessary to perform its obligations under the Proposal except as may be required by a court or governmental authority. Notwithstanding the foregoing, Confidential Information shall not include any information that is in the public domain or becomes publicly known through no fault of the receiving party, or is otherwise properly received from a third party without an obligation of confidentiality.

  1. RELATIONSHIP OF THE PARTIES

8.1 Independent Contractor. Developer is an independent contractor, not an employee of Client or any company affiliated with Client. Developer shall provide the Services under the general direction of Client, but Developer shall determine, in Developer’s sole discretion, the manner and means by which the Services are accomplished.

This Service Terms does not create a partnership or joint venture and neither party is authorized to act as agent or bind the other party except as expressly stated in this Service Terms. Developer and the work product or Deliverables prepared by Developer shall not be deemed a work for hire as that term is defined under Copyright Law. All rights, if any, granted to Client are contractual in nature and are wholly defined by the express written Service Terms of the parties and the various terms and conditions of this Service Terms.

8.2 Developer Agents. Developer shall be permitted to engage and/or use third party Developers or other service providers as independent contractors in connection with the Services (“Design Agents”). Notwithstanding, Developer shall remain fully responsible for such Design Agents’ compliance with the various terms and conditions of this Service Terms. 8.3 No Exclusivity. The parties expressly acknowledge that this Service Terms does not create an exclusive relationship between the parties. Client is free to engage others to perform services of the same or

similar nature to those provided by Developer, and Developer shall be entitled to offer and provide design services to others, solicit other clients and otherwise advertise the services offered by Developer.

  1. WARRANTIES AND REPRESENTATIONS

9.1 By Client. Client represents, warrants and covenants to Developer that

(a) Client owns all right, title, and interest in, or otherwise has full right and authority to permit the use of the Client Content,

(b) to the best of Client’s knowledge, the Client Content does not infringe the rights of any third party, and use of the Client Content as well as any Trademarks in connection with the Project does not and will not violate the rights of any third parties,

(c) Client shall comply with the terms and conditions of any licensing Service Termss which govern the use of Third Party Materials, and

(d) Client shall comply with all laws and regulations as they relate to the Services and Deliverables.

9.2 By Developer

(a) Developer hereby represents, warrants and covenants to Client that Developer will provide the Services identified in the Service Terms in a professional and workmanlike manner and in accordance with all reasonable professional standards for such services.

(b) Developer further represents, warrants and covenants to Client that (i) except for Third Party Materials and Client Content, the Final Deliverables shall be the original work of Developer and/or its independent contractors, (ii) in the event that the Final Deliverables include the work of independent contractors commissioned for the Project by Developer, Developer shall have secure Service Termss from such contractors granting all necessary rights, title, and interest in and to the Final Deliverables sufficient for Developer to grant the intellectual property rights provided in this Service Terms, and (iii) to the best of Developer’s knowledge, the Final Art provided by Developer and Developer’s subcontractors does not infringe the rights of any party, and use of same in connection with the Project will not violate the rights of any third parties. In the event Client or third parties modify or otherwise use the Deliverables outside of the scope or for any purpose not identified in the Proposal or this Service Terms or contrary to the terms and conditions noted herein, all representations and warranties of Developer shall be void.

(c) Except for the express representations and warranties stated in this Service Terms, Developer makes no warranties whatsoever. Developer explicitly disclaims any other warranties of any kind, either express or implied, including but not limited to warranties of merchantability or fitness for a particular purpose or compliance with laws or government rules or regulations applicable to the project.

(d) Project would be delivered within 20-60 business days from the date of initiation over the email confirmation for Project.

  1. INDEMNIFICATION/LIABILITY

10.1 By Client. Client agrees to indemnify, save and hold harmless Developer from any and all damages, liabilities, costs, losses or expenses arising out of any claim, demand, or action by a third party arising out of any breach of Client’s responsibilities or obligations, representations or warranties under this Service Terms. Under such circumstances Developer shall promptly notify Client in writing of any claim or suit;

(a) Client has sole control of the defense and all related settlement negotiations; and

(b) Developer provides Client with commercially reasonable assistance, information and authority necessary to perform Client’s obligations under this section. Client will reimburse the reasonable out-of-pocket expenses incurred by Developer in providing such assistance.

10.2 By Developer. Subject to the terms, conditions, express representations and warranties provided in this Service Terms, Developer agrees to indemnify, save and hold harmless Client from any and all damages, liabilities, costs, losses or expenses arising out of any finding of fact which is inconsistent with Developer’s representations and warranties made herein, except in the event any such claims, damages, liabilities, costs, losses or expenses arise directly as a result of gross negligence or misconduct of Client provided that

(a) Client promptly notifies Developer in writing of the claim;

(b) Developer shall have sole control of the defense and all related settlement negotiations; and

(c) Client shall provide Developer with the assistance, information and authority necessary to perform Developer’s obligations under this section. Notwithstanding the foregoing, Developer shall have no obligation to defend or otherwise indemnify Client for any claim or adverse finding of fact arising out of or due to Client Content, any unauthorized content, improper or illegal use, or the failure to update or maintain any Deliverables provided by Developer.

10.3 Limitation of Liability. The services and the work product of Developer are sold “as is.” In all circumstances, the maximum liability of Developer, its directors, officers, employees, design agents and affiliates (“Developer Parties”), to client for damages for any and all causes whatsoever, and client’s maximum remedy, regardless of the form of action, whether in contract, tort or otherwise, shall be limited to the net profit of Developer. In no event shall Developer be liable for any lost data or content, lost profits, business interruption or for any indirect, incidental, special, consequential, exemplary or punitive damages arising out of or relating to the materials or the services provided by Developer, even if Developer has been advised of the possibility of such damages, and notwithstanding the failure of essential purpose of any limited remedy.

  1. TERM AND TERMINATION

11.1 This Service Terms shall commence upon the Effective Date and shall remain effective until the Services are completed and delivered.

11.2 This Service Terms may be terminated at any time by either party effective immediately upon notice, or the mutual Service Terms of the parties, or if any party:

(a) becomes insolvent, files a petition in bankruptcy, makes an assignment for the benefit of its creditors; or

(b) Breaches any of its material responsibilities or obligations under this Service Terms, which breach is not remedied within 10 days from receipt of written notice of such breach.

11.3 In the event of termination, Developer shall be compensated for the Services performed through the date of termination in the amount of

(a) any advance payment,

(b) a prorated portion of the fees due, or

(c) hourly fees for work performed by Developer or Developer’s agents as of the date of termination, whichever is greater; and Client shall pay all Expenses, fees, out of pockets together with any Additional Costs incurred through and up to, the date of cancellation.

11.4 In the event of termination by Client and upon full payment of compensation as provided herein, Developer grants to Client such right and title as provided for in Schedule A of this Service Terms with respect to those Deliverables provided to, and accepted by Client as of the date of termination.

11.5 Upon expiration or termination of this Service Terms:

(a) each party shall return or, at the disclosing party’s request, destroy the Confidential Information of the other party, and

(b) other than as provided herein, all rights and obligations of each party under this Service Terms, exclusive of the Services, shall survive.

  1. GENERAL

12.1 Modification/Waiver. This Service Terms may be modified by the parties. Any modification of this Service Terms must be in writing, except that Developer’s invoices may include, and Client shall pay, expenses or costs that Client authorizes by electronic mail in cases of extreme time sensitivity. Failure by either party to enforce any right or seek to remedy any breach under this Service Terms shall not be construed as a waiver of such rights nor shall a waiver by either party of default in one or more instances be construed as constituting a continuing waiver or as a waiver of any other breach.

12.2 Notices. All notices to be given hereunder shall be transmitted in writing either by facsimile or electronic mail with return confirmation of receipt or by certified or registered mail, return receipt requested, and shall be sent to the addresses identified below, unless notification of change of address is given in writing. Notice shall be effective upon receipt or in the case of fax or email, upon confirmation of receipt.

12.3 No Assignment. Neither party may assign, whether in writing or orally, or encumber its rights or obligations under this Service Terms or permit the same to be transferred, assigned or encumbered by operation of law or otherwise, without the prior written consent of the other party.

12.4 Force Majeure. Developer shall not be deemed in breach of this Service Terms if Developer is unable to complete the Services or any portion thereof by reason of fire, earthquake, labor dispute, act of God or public enemy, death, illness or incapacity of Developer or any local, state, federal, national or international law, governmental order or regulation or any other event beyond Developer’s control (collectively, “Force Majeure Event”). Upon occurrence of any Force Majeure Event, Developer shall give notice to Client of its inability to perform or of delay in completing the Services and shall propose revisions to the schedule for completion of the Services.

12.5 Governing Law and Dispute Resolution. The formation, construction, performance and enforcement of this Service Terms shall be in accordance with the laws of India and the state of New Delhi without regard to its conflict of law provisions or the conflict of law provisions of any other jurisdiction. In the event of a dispute arising out of this Service Terms, the parties agree to attempt to resolve any dispute by negotiation between the parties. If they are unable to resolve the dispute, either party may commence mediation and/or binding arbitration through the Indian Council of Arbitration, or other forum mutually agreed to by the parties. The prevailing party in any dispute resolved by binding arbitration or litigation shall be entitled to recover its attorneys’ fees and costs. In all other circumstances, the parties specifically consent to the local, state and federal courts located in the state of New Delhi. The parties hereby waive any jurisdictional or venue defenses available to them and further consent to service of process by mail. Client acknowledges that Developer will have no adequate remedy at law in the event Client uses the deliverables in any way not permitted hereunder, and hereby agrees that Developer shall be entitled to equitable relief by way of temporary and permanent injunction, and such other and further relief at law or equity as any arbitrator or court of competent jurisdiction may deem just and proper, in addition to any and all other remedies provided for herein.

12.6 Severability. Whenever possible, each provision of this Service Terms shall be interpreted in such manner as to be effective and valid under applicable law, but if any provision of this Service Terms is held invalid or unenforceable, the remainder of this Service Terms shall nevertheless remain in full force and effect and the invalid or unenforceable provision shall be replaced by a valid or enforceable provision.

12.7 Headings. The numbering and captions of the various sections are solely for convenience and reference only and shall not affect the scope, meaning, intent or interpretation of the provisions of this Service Terms nor shall such headings otherwise be given any legal effect.

12.8 Integration. This Service Terms comprises the entire understanding of the parties hereto on the subject matter herein contained, and supersedes and merges all prior and contemporaneous Service Termss, understandings and discussions between the parties relating to the subject matter of this Service Terms. In the event of a conflict between the Proposal and any other Service Terms documents, the terms of the Proposal shall control. This Service Terms comprises this Basic Terms and Conditions document, the Proposal, Schedule A and Schedule B below.

By their execution, the parties hereto have agreed to all of the terms and conditions of this Service Terms effective as of the last date of signature, and each signatory represents that it has the full authority to enter into this Service Terms and to bind her/his respective party to all of the terms and conditions herein. Schedule B: Interactive-specific Terms and Conditions

  1. SUPPORT SERVICES

13.1 Developer would provide 1 year of free support services where Developer would fix all the issues arising which are related to the development part, except client caused issues and no modifications which were never agreed upon earlier.

13.2 Support is given solely on non-sharing basis, that means, the client will not get developer level access or cpanel access to modify website files till the time Annual Maintenance Contract (AMC) is active.

13.3. Client reserves the right to end the AMC anytime before 2 months of the AMC renewal date & he shall be entitled to receive the website files within 4 to 72 business hours.

13.4 In case of terminating the AMC within 60 days before the renewal date, client is liable to pay the entire AMC fee whether or not he wishes to continue with the AMC plan.

13.5 Under AMC support, developer offers support related to any issues arriving from the developer or server end and not for the issues or mistakenly content deletion from the client end.

13.6 Developer keeps regular backups for the websites but does not guarantee for 100% successful backup restoration.

13.7 For any additional tasks or modifications, additional charges would be levied depending upon the nature of the modification.

13.8 If emails are being hosted outside our servers, no support is provided for the same.

  1. ENHANCEMENTS

14.1 During the Maintenance Period, Client may request that Developer develop enhancements to the Deliverables, and Developer shall exercise commercially reasonable efforts to prioritize Developer’s resources to create such enhancements. The parties understand that preexisting obligations to third parties existing on the date of the request for enhancements may delay the immediate execution of any such requested enhancements. Such enhancements shall be provided on a time and materials basis at Developer’s then in effect price for such services.